Terms of Trade
1. Definitions
1.1 “Contract” means the terms and conditions contained herein, together with any Quotation, order, invoice or other document or amendments expressed to be supplemental to this Contract.
1.2 “Supplier” means Rivers Edge Services Ltd, its successors and assigns or any person acting on behalf of and with the authority of Rivers Edge Services Ltd.
1.3 “Customer” means the person/s, entities or any person acting on behalf of and with the authority of the Customer requesting the Supplier to provide the Services as specified in any proposal, quotation, order, invoice or other documentation, and:
(a) if there is more than one Customer, is a reference to each Customer jointly and severally; and
(b) if the Customer is a partnership, it shall bind each partner jointly and severally; and
(c) if the Customer is a part of a Trust, shall be bound in their capacity as a trustee; and
(d) includes the Customer’s executors, administrators, successors and permitted assigns.
1.4 “Goods” means all Goods or Services supplied by the Supplier to the Customer at the Customer’s request from time to time (where the context so permits the terms ‘Goods’ or ‘Services’ shall be interchangeable for the other).
1.5 "Confidential Information” means information of a confidential nature whether oral, written or in electronic form including, but not limited to, this Contract, either party’s intellectual property, operational information, know-how, trade secrets, financial and commercial affairs, contracts, client information (including but not limited to, “Personal Information” such as: name, address, D.O.B, occupation, driver’s license details, electronic contact (email, Facebook or Twitter details), medical insurance details or next of kin and other contact information (where applicable), previous credit applications, credit history) and pricing details.
1.6 “Cookies” means small files which are stored on a user’s computer. They are designed to hold a modest amount of data (including Personal Information) specific to a particular client and website, and can be accessed either by the web server or the client’s computer. If the Customer does not wish to allow Cookies to operate in the background when ordering from the website, then the Customer shall have the right to enable / disable the Cookies first by selecting the option to enable / disable provided on the website, prior to ordering Goods via the website.
1.7 “Price” means the Price payable (plus any Goods and Services Tax (“GST”) where applicable) for the Goods as agreed between the Supplier and the Customer in accordance with clause 5 below.
1.8 “COVID-19” an infectious disease caused by the SARS-CoV-2 virus. Including all variants.
2. Acceptance
2.1 The Customer is taken to have exclusively accepted and is immediately bound, jointly and severally, by these terms and conditions if the Customer places an order for or accepts delivery of the Goods and/or Services.
2.2 In the event of any inconsistency between the terms and conditions of this Contract and any other prior document or schedule that the parties have entered into, the terms of this Contract shall prevail.
2.3 Any amendment to the terms and conditions contained in this Contract may only be amended in writing by the consent of both parties.
2.4 The Customer acknowledges that the supply of Goods on credit shall not take effect until the Customer has completed a credit application with the Supplier and it has been approved with a credit limit established for the account.
2.5 In the event that the supply of Goods request exceeds the Buyers credit limit and/or the account exceeds the payment terms, the Supplier reserves the right to refuse delivery.
2.6 Electronic signatures shall be deemed to be accepted by either party providing that the parties have complied with Section 226 of the Contract and Commercial Law Act 2017 or any other applicable provisions of that Act or any Regulations referred to in that Act.
2.7 These terms and conditions may be meant to be read in conjunction with the Supplier’s Hire Form, and:
(a) where the context so permits, the terms ‘Goods’ or ‘Services’ shall include any supply of Equipment, as defined therein; and
(b) if there are any inconsistencies between the two documents then the terms and conditions contained therein shall prevail.
3. Errors and Omissions
3.1 The Customer acknowledges and accepts that the Supplier shall, without prejudice, accept no liability in respect of any alleged or actual error(s) and/or omission(s):
(a) resulting from an inadvertent mistake made by the Supplier in the formation and/or administration of this Contract; and/or
(b) contained in/omitted from any literature (hard copy and/or electronic) supplied by the Supplier in respect of the Services.
3.2 In the event such an error and/or omission occurs in accordance with clause 3.1, and is not attributable to the negligence and/or wilful misconduct of the Supplier; the Customer shall not be entitled to treat this Contract as repudiated nor render it invalid.
4. Change in Control
4.1 The Customer shall give the Supplier not less than fourteen (14) days prior written notice of any proposed change of ownership of the Customer and/or any other change in the Customer’s details (including but not limited to, changes in the Customer’s name, address and contact phone or fax number/s, change of trustees or business practice). The Customer shall be liable for any loss incurred by the Supplier as a result of the Customer’s failure to comply with this clause.
5. Price and Payment
5.1 At the Supplier’s sole discretion the Price shall be either:
(a) as indicated on any invoice provided by the Supplier to the Customer; or
(b) the Supplier’s quoted price (subject to clause 5.2) which will be valid for the period stated in the quotation or otherwise for a period of thirty (30) days.
5.2 The Supplier reserves the right to change the Price:
(a) if a variation to the Goods which are to be supplied is requested; or
(b) if a variation to the Services originally scheduled (including any applicable plans or specifications) is requested; or
(c) where additional Services are required due to the discovery of hidden or unidentifiable difficulties (including, but not limited to, poor weather conditions, limitations to accessing the site, availability of machinery, safety considerations, prerequisite work by any third party not being completed, change of design, hidden pipes and wiring in walls etc.) which are only discovered on commencement of the Services; or
(d) in the event of increases to the Supplier in the cost of labour or Goods which are beyond the Supplier’s control.
5.3 Variations will be charged for on the basis of the Supplier’s quotation, and will be detailed in writing, and shown as variations on the Supplier’s invoice. The Customer shall be required to respond to any variation submitted by the Supplier within ten (10) working days. Failure to do so will entitle the Supplier to add the cost of the variation to the Price. Payment for all variations must be made in full at the time of their completion.
5.4 At the Supplier’s sole discretion a deposit may be required.
5.5 The Customer acknowledges and accepts that a minimum charge of one half hour’s labour shall apply to all invoices.
5.6 Time for payment for the Goods being of the essence, the Price will be payable by the Customer on the date/s determined by the Supplier, which may be:
(a) by way of instalments/progress payments in accordance with the Supplier’s payment schedule;
(b) for certain approved Buyers, due twenty (20) days following the end of the month in which a statement is posted to the Customer’s address or address for notices;
(c) the date specified on any invoice or other form as being the date for payment; or
(d) failing any notice to the contrary, the date which is seven (7) days following the date of any invoice given to the Customer by the Supplier.
5.7 At the agreement of both parties, payment of the Price may be subject to retention by the Customer of an amount (hereafter called the "Retention Money"), being a set amount or equal to a percentage of the Price. The Customer shall hold the Retention Money for the agreed period following completion of the Services during which time all Services are to be completed and/or all defects are to be remedied. Any Retention Money applicable to this Contract is to be dealt with in accordance with section 18 of the Construction Contracts Act 2002.
5.8 Payment may be made by electronic/on-line banking or by any other method as agreed to between the Customer and the Supplier.
5.9 The Supplier may in its discretion allocate any payment received from the Customer towards any invoice that the Supplier determines and may do so at the time of receipt or at any time afterwards. On any default by the Customer the Supplier may re-allocate any payments previously received and allocated. In the absence of any payment allocation by the Supplier, payment will be deemed to be allocated in such manner as preserves the maximum value of the Supplier’s Purchase Money Security Interest (as defined in the PPSA) in the Goods.
5.10 The Customer shall not be entitled to set off against, or deduct from the Price, any sums owed or claimed to be owed to the Customer by the Supplier nor to withhold payment of any invoice because part of that invoice is in dispute unless the request for payment by the Supplier is a claim made under the Construction Contracts Act 2002.
5.11 Unless otherwise stated the Price does not include GST. In addition to the Price, the Customer must pay to the Supplier an amount equal to any GST the Supplier must pay for any supply by the Supplier under this or any other agreement for the sale of the Goods. The Customer must pay GST, without deduction or set off of any other amounts, at the same time and on the same basis as the Customer pays the Price. In addition, the Customer must pay any other taxes and duties that may be applicable in addition to the Price except where they are expressly included in the Price.
6. Delivery
6.1 Subject to clause 6.2 it is the Supplier’s responsibility to ensure that the Services start as soon as it is reasonably possible.
6.2 The Services’ commencement date will be put back and/or the completion date extended by whatever time is reasonable in the event that the Supplier claims an extension of time (by giving the Customer written notice) where completion is delayed by an event beyond the Supplier’s control, including but not limited to any failure by the Customer to:
(a) make a selection; or
(b) have the site ready for the Services; or
(c) notify the Supplier that the site is ready.
6.3 At the Supplier’s sole discretion the cost of delivery is either included in the Price or is in addition to the Price.
6.4 The Supplier may deliver the Goods in separate instalments. Each separate instalment shall be invoiced and paid in accordance with the provisions in these terms and conditions.
6.5 Any time specified by the Supplier for delivery of the Goods is an estimate only and the Supplier will not be liable for any loss or damage incurred by the Customer as a result of delivery being late. However both parties agree that they shall make every endeavour to enable the Goods to be delivered at the time and place as was arranged between both parties. In the event that the Supplier is unable to supply the Goods as agreed solely due to any action or inaction of the Customer, then the Supplier shall be entitled to charge a reasonable fee for redelivery and/or storage.
7. Risk
7.1 If the Supplier retains ownership of the Goods under clause 13 then:
(a) where the Supplier is supplying Goods only, all risk for the Goods shall immediately pass to the Customer on delivery and the Customer must insure the Goods on or before delivery. Delivery of the Goods shall be deemed to have taken place immediately at the time that the Goods are delivered by the Supplier or the Supplier’s nominated carrier to the Customer’s nominated delivery address (even if the Customer is not present at the address); or
(b) where the Supplier is to both supply and install Goods then the Supplier shall maintain a contract works insurance policy (if applicable) until the Services are completed. Upon completion of the Services all risk for the Services shall immediately pass to the Customer.
7.2 Notwithstanding the provisions of clause 7.1 if the Customer specifically requests the Supplier to leave Goods outside the Supplier’s premises for collection or to deliver the Goods to an unattended location then such materials shall always be left at sole risk of the Customer and it shall be the Customer’s responsibility to ensure the Goods are insured adequately or at all. In the event that such Goods are lost, damaged or destroyed then replacement of the Goods shall be at the Customer’s expense.
7.3 Where the Supplier is required to install the Goods the Customer warrants that the structure of the premises or equipment in or upon which these Goods are to be installed or erected is sound and will sustain the installation and work incidental thereto and the Supplier shall not be liable for any claims, demands, losses, damages, costs and expenses howsoever caused or arising in connection with the installation and work incidental thereto.
7.4 Where the Customer has supplied materials for the Supplier to complete the Services, the Customer acknowledges that the Supplier shall have the opportunity to inspect the materials prior to the commencement of the Services. In the event that, in the Supplier’s opinion, the materials supplied do not meet New Zealand safety standards or are not suitable for the nature of the Services, the Supplier may refuse to install the materials, and shall not be liable for any loss or damage or additional costs incurred by the Customer as a result.
7.5 The Customer acknowledges that the Supplier is only responsible for parts that are replaced by the Supplier and that in the event that other parts/Goods, subsequently fail, the Customer agrees to indemnify the Supplier against any loss or damage to the Goods, or caused by the Goods, or any part thereof howsoever arising.
7.6 Any advice, recommendation, information, assistance or service provided by the Supplier in relation to Goods or Services supplied is given in good faith, is based on the Suppliers own knowledge and experience and shall be accepted without liability on the part of the Supplier and it shall be the responsibility of the Customer to confirm the accuracy and reliability of the same in light of the use to which the Customer makes or intends to make of the Goods or Services.
7.7 All work will be tested to ensure that it is electrically safe and is in accordance with the wiring rules and other standards applying to the electrical installation under the Electrical Safety Act, Regulations and Codes of Practice. All of the cabling work will comply with the Australian and New Zealand Wiring standards.
7.8 The Customer acknowledges and agree that where the Supplier has performed temporary repairs on the unit that:
(a) the Supplier offers no guarantee against the reoccurrence of the initial fault, or any further damage caused; and
(b) the Supplier will immediately advise the Customer of the fault and shall provide the Customer with an estimate for the full repair of the damaged unit.
7.9 The Customer acknowledges that Goods supplied may:
(a) fade or change colour over time; and
(b) expand, contract or distort as a result of exposure to heat, cold, weather; and
(c) mark or stain if exposed to certain substances; and
(d) be damaged or disfigured by impact or scratching; and
(e) that lamps or fittings may fail before the manufacturer’s stated lifetime expires.
8. Specifications
8.1 The Customer acknowledges that all descriptive specifications, illustrations, drawings, data, dimensions, ratings and weights stated in the Supplier’s or the manufacturer’s fact sheets, price lists or advertising material, are approximate only and are given by way of identification only. The Customer shall not be entitled to rely on such information, and any use of such does not constitute a sale by description, and does not form part of the contract, unless expressly stated as such in writing by the Supplier.
9. Customer’s Responsibilities
9.1 The Customer acknowledges that in the event asbestos or any other toxic substances are discovered at the site that it is their responsibility to ensure the safe removal of the same. The Customer further agrees to indemnify the Supplier against any costs incurred by the Supplier as a consequence of such discovery. Under no circumstances will the Supplier handle or remove asbestos product or toxic substances.
10. Access
10.1 The Customer shall ensure that the Supplier has clear and free access to the site at all times to enable them to undertake the Services. The Supplier shall not be liable for any loss or damage to the site (including, without limitation, damage to pathways, driveways and concreted or paved or grassed areas) unless due to the negligence of the Supplier.
11. Underground Locations
11.1 Prior to the Supplier commencing any work the Customer must advise the Supplier of the precise location of all underground services on the site and clearly mark the same. The underground mains and services the Customer must identify include, but are not limited to, electrical services, gas services, sewer services, pumping services, sewer connections, sewer sludge mains, water mains, irrigation pipes, telephone cables, fibre optic cables, oil pumping mains, and any other services that may be on site.
11.2 Whilst the Supplier will take all care to avoid damage to any underground services the Customer agrees to indemnify the Supplier in respect of all and any liability claims, loss, damage, costs and fines as a result of damage to services not precisely located and notified as per clause 11.1.
12. Compliance with Laws
12.1 The Customer and the Supplier shall comply with the provisions of all statutes, regulations and bylaws of government, local and other public authorities that may be applicable to the Services, including any WorkSafe and health and safety laws relating to building/construction sites and any other relevant safety standards or legislation.
12.2 The Customer shall:
(a) be liable for any costs incurred by the Supplier due to the Customer’s failure to comply with clause 12.1; and
(b) reimburse or pay for any additional costs incurred by the Supplier in meeting health and safety requirements; and
(c) indemnify the Supplier against all costs or losses that the Customer may incur due to compliance requirements which result in delays or prevents the Supplier from completing the Services; and
(d) obtain (at the expense of the Customer) all licenses and approvals that may be required for the Services; and
12.3 Notwithstanding clause 12.1 and pursuant to the Health & Safety at Work Act 2015 (the “HSW Act”) the Supplier agrees at all times comply with sections 28 and 34 of the “HSW Act” with meeting their obligations for health and safety laws in the workplace regardless of whether they may be the party in control of the site or where they may be acting as a subcontractor for the Customer who has engaged a thirty party head contractor.
12.4 If during the course of installation when the Services are being conducted within and around switchboards and/or other components, that if the same is found defective or deemed to be unsafe by the Supplier, then the Supplier shall notify the Customer immediately. The power if isolated will not be re-energised until such time as the existing condition has been rectified and made safe in accordance to the Electrical Safety Regulations. The Customer accepts and agrees that any costs associated with the rectification work including any Goods and labour shall be to the Customer’s account.
12.5 Any live work or Services undertaken near live conductors where it is safe to do so shall be dealt with in accordance with Australian and New Zealand Wiring standards being “Safe working on Low Voltage Electrical Installations, relevant Commonwealth and Statutory Acts and Work Place Regulations”. The Customer live work procedures are designed to eliminate risk of injury to the Customer’s employees, damage to the Customer’s installations and unexpected power disconnections. It may in some cases require disconnection and isolation of the installation to undertake such Services for which additional charges may be applicable. This shall be invoiced in accordance with clause 5.2.
13. Title
13.1 The Supplier and the Customer agree that ownership of the Goods shall not pass until:
(a) the Customer has paid the Supplier all amounts owing to the Supplier; and
(b) the Customer has met all of its other obligations to the Supplier.
13.2 Receipt by the Supplier of any form of payment other than cash shall not be deemed to be payment until that form of payment has been honoured, cleared or recognised.
13.3 It is further agreed that until ownership of the Goods passes to the Customer in accordance with clause 13.1:
(a) the Customer is only a bailee of the Goods and must return the Goods to the Supplier on request;
(b) the Customer holds the benefit of the Customer’s insurance of the Goods on trust for the Supplier and must pay to the Supplier the proceeds of any insurance in the event of the Goods being lost, damaged or destroyed;
(c) the Customer must not sell, dispose, or otherwise part with possession of the Goods other than in the ordinary course of business and for market value. If the Customer sells, disposes or parts with possession of the Goods then the Customer must hold the proceeds of any such act on trust for the Supplier and must pay or deliver the proceeds to the Supplier on demand;
(d) the Customer should not convert or process the Goods or intermix them with other goods but if the Customer does so then the Customer holds the resulting product on trust for the benefit of the Supplier and must sell, dispose of or return the resulting product to the Supplier as it so directs;
(e) the Customer irrevocably authorises the Supplier to enter any premises where the Supplier believes the Goods are kept and recover possession of the Goods;
(f) the Supplier may recover possession of any Goods in transit whether or not delivery has occurred;
(g) the Customer shall not charge or grant an encumbrance over the Goods nor grant nor otherwise give away any interest in the Goods while they remain the property of the Supplier;
(h) the Supplier may commence proceedings to recover the Price of the Goods sold notwithstanding that ownership of the Goods has not passed to the Customer.
14. Personal Property Securities Act 1999 (“PPSA”)
14.1 Upon assenting to these terms and conditions in writing the Customer acknowledges and agrees that:
(a) these terms and conditions constitute a security agreement for the purposes of the PPSA; and
(b) a security interest is taken in all Goods and/or collateral (account) – being a monetary obligation of the Customer to the Supplier for Services – that have previously been supplied and that will be supplied in the future by the Supplier to the Customer.
14.2 The Customer undertakes to:
(a) sign any further documents and/or provide any further information (such information to be complete, accurate and up-to-date in all respects) which the Supplier may reasonably require to register a financing statement or financing change statement on the Personal Property Securities Register;
(b) indemnify, and upon demand reimburse, the Supplier for all expenses incurred in registering a financing statement or financing change statement on the Personal Property Securities Register or releasing any Goods charged thereby;
(c) not register, or permit to be registered, a financing statement or a financing change statement in relation to the Goods and/or collateral (account) in favour of a third party without the prior written consent of the Supplier; and
(d) immediately advise the Supplier of any material change in its business practices of selling the Goods which would result in a change in the nature of proceeds derived from such sales.
14.3 The Supplier and the Customer agree that nothing in sections 114(1)(a), 133 and 134 of the PPSA shall apply to these terms and conditions.
14.4 The Customer waives its rights as a debtor under sections 116, 120(2), 121, 125, 126, 127, 129, 131 and 132 of the PPSA.
14.5 Unless otherwise agreed to in writing by the Supplier, the Customer waives its right to receive a verification statement in accordance with section 148 of the PPSA.
14.6 The Customer shall unconditionally ratify any actions taken by the Supplier under clauses 14.1 to 14.5.
14.7 Subject to any express provisions to the contrary (including those contained in this clause 14), nothing in these terms and conditions is intended to have the effect of contracting out of any of the provisions of the PPSA.
15. Security and Charge
15.1 In consideration of the Supplier agreeing to supply the Goods, the Customer charges all of its rights, title and interest (whether joint or several) in any land, realty or other assets capable of being charged, owned by the Customer either now or in the future, to secure the performance by the Customer of its obligations under these terms and conditions (including, but not limited to, the payment of any money).
15.2 The Customer indemnifies the Supplier from and against all the Supplier’s costs and disbursements including legal costs on a solicitor and own client basis incurred in exercising the Supplier’s rights under this clause.
15.3 The Customer irrevocably appoints the Supplier and each director of the Supplier as the Customer’s true and lawful attorney/s to perform all necessary acts to give effect to the provisions of this clause 15 including, but not limited to, signing any document on the Customer’s behalf.
16. Defects
16.1 The Customer shall inspect the Goods on delivery and shall within seven (7) days of delivery (time being of the essence) notify the Supplier of any alleged defect, shortage in quantity, damage or failure to comply with the description or quote. The Customer shall afford the Supplier an opportunity to inspect the Goods within a reasonable time following delivery if the Customer believes the Goods are defective in any way. If the Customer shall fail to comply with these provisions the Goods shall be presumed to be free from any defect or damage. For defective Goods, which the Supplier has agreed in writing that the Customer is entitled to reject, the Supplier’s liability is limited to either (at the Supplier’s discretion) replacing the Goods or repairing the Goods.
16.2 Goods will not be accepted for return other than in accordance with 16.1 above, and provided that:
(a) the Supplier has agreed in writing to accept the return of the Goods; and
(b) the Goods are returned at the Customer’s cost within seven (7) days of the delivery date; and
(c) the Supplier will not be liable for Goods which have not been stored or used in a proper manner; and
(d) the Goods are returned in the condition in which they were delivered and with all packaging material, brochures and instruction material in as new condition as is reasonably possible in the circumstances.
17. Warranty
17.1 Subject to the conditions of warranty set out in clause 17.2 the Supplier warrants that if any defect in any workmanship of the Supplier becomes apparent and is reported to the Supplier within twelve (12) months of the date of delivery (time being of the essence) then the Supplier will either (at the Supplier’s sole discretion) replace or remedy the workmanship.
17.2 The conditions applicable to the warranty given by clause 17.1 are:
(a) the warranty shall not cover any defect or damage which may be caused or partly caused by or arise through:
(i) failure on the part of the Customer to properly maintain any Goods; or
(ii) failure on the part of the Customer to follow any instructions or guidelines provided by the Supplier; or
(iii) any use of any Goods otherwise than for any application specified on a quote or order form; or
(iv) the continued use of any Goods after any defect becomes apparent or would have become apparent to a reasonably prudent operator or user; or
(v) fair wear and tear, any accident or act of God.
(b) the warranty shall cease and the Supplier shall thereafter in no circumstances be liable under the terms of the warranty if the workmanship is repaired, altered or overhauled without the Supplier’s consent.
(c) in respect of all claims the Supplier shall not be liable to compensate the Customer for any delay in either replacing or remedying the workmanship or in properly assessing the Customer’s claim.
17.3 For Goods not manufactured by the Supplier, the warranty shall be the current warranty provided by the manufacturer of the Goods. The Supplier shall not be bound by nor be responsible for any term, condition, representation or warranty other than that which is given by the manufacturer of the Goods.
18. Consumer Guarantees Act 1993
18.1 If the Customer is acquiring Goods for the purposes of a trade or business, the Customer acknowledges that the provisions of the Consumer Guarantees Act 1993 do not apply to the supply of Goods by the Supplier to the Customer.
19. Intellectual Property
19.1 Where the Supplier has designed, drawn or developed Goods for the Customer, then the copyright in any designs and drawings and documents shall remain the property of the Supplier. Under no circumstances may such designs, drawings and documents be used without the express written approval of the Supplier.
19.2 The Customer warrants that all designs, specifications or instructions given to the Supplier will not cause the Supplier to infringe any patent, registered design or trademark in the execution of the Customer’s order and the Customer agrees to indemnify the Supplier against any action taken by a third party against the Supplier in respect of any such infringement.
19.3 The Customer agrees that the Supplier may (at no cost) use for the purposes of marketing or entry into any competition, any documents, designs, drawings or Goods which the Supplier has created for the Customer.
20. Default and Consequences of Default
20.1 Interest on overdue invoices shall accrue daily from the date when payment becomes due, until the date of payment, at a rate of three percent (3.0%) per calendar month (and at the Supplier’s sole discretion such interest shall compound monthly at such a rate) after as well as before any judgment.
20.2 If the Customer owes the Supplier any money the Customer shall indemnify the Supplier from and against all costs and disbursements incurred by the Supplier in recovering the debt (including but not limited to internal administration fees, legal costs on a solicitor and own client basis, the Supplier’s collection agency costs, and bank dishonour fees).
20.3 Further to any other rights or remedies the Supplier may have under this Contract, if a Customer has made payment to the Supplier, and the transaction is subsequently reversed, the Customer shall be liable for the amount of the reversed transaction, in addition to any further costs incurred by the Supplier under this clause 20 where it can be proven that such reversal is found to be illegal, fraudulent or in contravention to the Customer’s obligations under this Contract.
20.4 Without prejudice to the Supplier’s other remedies at law the Supplier shall be entitled to cancel all or any part of any order of the Customer which remains unfulfilled and all amounts owing to the Supplier shall, whether or not due for payment, become immediately payable if:
(a) any money payable to the Supplier becomes overdue, or in the Supplier’s opinion the Customer will be unable to make a payment when it falls due;
(b) the Customer has exceeded any applicable credit limit provided by the Supplier;
(c) the Customer becomes insolvent, convenes a meeting with its creditors or proposes or enters into an arrangement with creditors, or makes an assignment for the benefit of its creditors; or
(d) a receiver, manager, liquidator (provisional or otherwise) or similar person is appointed in respect of the Customer or any asset of the Customer.
21. Cancellation
21.1 Without prejudice to any other rights or remedies the Supplier may have, if at any time the Customer is in breach of any obligation (including those relating to payment and/or failure to remedy any breach in respect of this Contract within ten (10) working days of receipt by the Customer of such notice/s) then the Supplier may suspend the supply of Goods and/or Services immediately. The Supplier will not be liable to the Customer for any loss or damage the Customer suffers because the Supplier has exercised its rights under this clause.
21.2 The Supplier may cancel any contract to which these terms and conditions apply or cancel delivery of Goods at any time before the Goods are delivered by giving written notice to the Customer. On giving such notice the Supplier shall repay to the Customer any money paid by the Customer for the Goods. The Supplier shall not be liable for any loss or damage whatsoever arising from such cancellation.
21.3 In the event that the Customer cancels delivery of Goods the Customer shall be liable for any and all loss incurred (whether direct or indirect) by the Supplier as a direct result of the cancellation (including, but not limited to, any loss of profits).
21.4 Cancellation of orders for Goods made to the Customer’s specifications, or for non-stocklist items, will definitely not be accepted once production has commenced, or an order has been placed.
22. Privacy Policy
22.1 All emails, documents, images or other recorded information held or used by the Supplier is Personal Information as defined and referred to in clause 22.3 and therefore considered confidential. The Supplier acknowledges its obligation in relation to the handling, use, disclosure and processing of Personal Information pursuant to the Privacy Act 1993 (“the Act”) including Part II of the OECD Guidelines and as set out in Schedule 5A of the Act and any statutory requirements where relevant in a European Economic Area “EEA” then the EU Data Privacy Laws (including the General Data Protection Regulation “GDPR”) (collectively, “EU Data Privacy Laws”). The Supplier acknowledges that in the event it becomes aware of any data breaches and/or disclosure of the Buyers Personal Information, held by the Supplier that may result in serious harm to the Customer, the Supplier will notify the Customer in accordance with the Act and/or the GDPR. Any release of such Personal Information must be in accordance with the Act and the GDPR (where relevant) and must be approved by the Customer by written consent, unless subject to an operation of law.
22.2 Notwithstanding clause 22.1, privacy limitations will extend to the Supplier in respect of Cookies where transactions for purchases/orders transpire directly from the Supplier’s website. The Supplier agrees to display reference to such Cookies and/or similar tracking technologies, such as pixels and web beacons (if applicable), such technology allows the collection of Personal Information such as the Customer’s:
(a) IP address, browser, email client type and other similar details;
(b) tracking website usage and traffic; and
(c) reports are available to the Supplier when the Supplier sends an email to the Customer, so the Supplier may collect and review that information (“collectively Personal Information”)
In order to enable / disable the collection of Personal Information by way of Cookies, the Customer shall have the right to enable / disable the Cookies first by selecting the option to enable / disable, provided on the website prior to proceeding with a purchase/order via the Supplier’s website.
22.3 The Customer authorises the Supplier or the Supplier’s agent to:
(a) access, collect, retain and use any information about the Customer;
(i) (including, name, address, D.O.B, occupation, driver’s license details, electronic contact (email, Facebook or Twitter details), medical insurance details or next of kin and other contact information (where applicable), previous credit applications, credit history or any overdue fines balance information held by the Ministry of Justice) for the purpose of assessing the Customer’s creditworthiness; or
(ii) for the purpose of marketing products and services to the Customer.
(b) disclose information about the Customer, whether collected by the Supplier from the Customer directly or obtained by the Supplier from any other source, to any other credit provider or any credit reporting agency for the purposes of providing or obtaining a credit reference, debt collection or notifying a default by the Customer.
22.4 Where the Customer is an individual the authorities under clause 22.3 are authorities or consents for the purposes of the Privacy Act 1993.
22.5 The Customer shall have the right to request the Supplier for a copy of the Personal Information about the Customer retained by the Supplier and the right to request the Supplier to correct any incorrect Personal Information about the Customer held by the Supplier.
23. Suspension of Services
23.1 Where the Contract is subject to the Construction Contracts Act 2002, the Customer hereby expressly acknowledges that:
(a) the Supplier has the right to suspend work within five (5) working days of written notice of its intent to do so if a payment claim is served on the Customer, and:
(i) the payment is not paid in full by the due date for payment in accordance with clause 5.6 and/or any subsequent amendments or new legislation and no payment schedule has been given by the Customer; or
(ii) a scheduled amount stated in a payment schedule issued by the Customer in relation to the payment claim is not paid in full by the due date for its payment; or
(iii) the Customer has not complied with an adjudicator’s notice that the Customer must pay an amount to the Supplier by a particular date; and
(iv) the Supplier has given written notice to the Customer of its intention to suspend the carrying out of construction work under the construction Contract.
(b) if the Supplier suspends work, it:
(i) is not in breach of Contract; and
(ii) is not liable for any loss or damage whatsoever suffered, or alleged to be suffered, by the Customer or by any person claiming through the Customer; and
(iii) is entitled to an extension of time to complete the Contract; and
(iv) keeps its rights under the Contract including the right to terminate the Contract; and may at any time lift the suspension, even if the amount has not been paid or an adjudicator’s determination has not been complied with.
(c) if the Supplier exercises the right to suspend work, the exercise of that right does not:
(i) affect any rights that would otherwise have been available to the Supplier under the Contract and Commercial Law Act 2017; or
(ii) enable the Customer to exercise any rights that may otherwise have been available to the Customer under that Act as a direct consequence of the Supplier suspending work under this provision;
(d) due to any act or omission by the Customer, the Customer effectively precludes the Supplier from continuing the Services or performing or complying with the Supplier’s obligations under this Contract, then without prejudice to the Supplier’s other rights and remedies, the Supplier may suspend the Services immediately after serving on the Customer a written notice specifying the payment default or the act, omission or default upon which the suspension of the Services is based. All costs and expenses incurred by the Supplier as a result of such suspension and recommencement shall be payable by the Customer as if they were a variation.
23.2 If pursuant to any right conferred by this Contract, the Supplier suspends the Services and the default that led to that suspension continues un-remedied subject to clause 21.1 for at least ten (10) working days, the Supplier shall be entitled to terminate the Contract, in accordance with clause 21.1.
24. Service of Notices
24.1 Any written notice given under this Contract shall be deemed to have been given and received:
(a) by handing the notice to the other party, in person;
(b) by leaving it at the address of the other party as stated in this Contract;
(c) by sending it by registered post to the address of the other party as stated in this Contract;
(d) if sent by facsimile transmission to the fax number of the other party as stated in this Contract (if any), on receipt of confirmation of the transmission;
(e) if sent by email to the other party’s last known email address.
24.2 Any notice that is posted shall be deemed to have been served, unless the contrary is shown, at the time when by the ordinary course of post, the notice would have been delivered.
25. Trusts
25.1 If the Customer at any time upon or subsequent to entering in to the Contract is acting in the capacity of trustee of any trust (“Trust”) then whether or not the Supplier may have notice of the Trust, the Customer covenants with the Supplier as follows:
(a) the Contract extends to all rights of indemnity which the Customer now or subsequently may have against the Trust and the trust fund;
(b) the Customer has full and complete power and authority under the Trust to enter into the Contract and the provisions of the Trust do not purport to exclude or take away the right of indemnity of the Customer against the Trust or the trust fund. The Customer will not release the right of indemnity or commit any breach of trust or be a party to any other action which might prejudice that right of indemnity;
(c) the Customer will not without consent in writing of the Supplier (the Supplier will not unreasonably withhold consent), cause, permit, or suffer to happen any of the following events:
(i) the removal, replacement or retirement of the Customer as trustee of the Trust;
(ii) any alteration to or variation of the terms of the Trust;
(iii) any advancement or distribution of capital of the Trust; or
(iv) any resettlement of the trust property.
26. Corona virus disease (COVID-19)
26.1 The Customer agrees to present valid proof of current COVID-19 vaccination or exemption upon request. This must be in the form prescribed by the Ministry of Health or a signed declaration.
(a) If the Customer does not present valid proof of current vaccination or exemption, the Supplier reserves the right to suspend or cancel work immediately and without notice as per clause 21.
(b) If the Supplier agrees to continue the work, the Customer must abide by all current Government recommendations, requirements or mandates regarding COVID-19. This includes the practice of social distancing and wearing of face masks.
26.2 The Customer shall be liable for any additional costs for infection control and employee / public safety in relation to preventing the Spread of COVID-19.
27. General
27.1 Any dispute or difference arising as to the interpretation of these terms and conditions or as to any matter arising hereunder, shall be submitted to, and settled by, either adjudication in accordance with the Construction Contracts Act 2002 and/or by arbitration in accordance with the Arbitration Act 1996 or its replacement(s).
27.2 The failure by either party to enforce any provision of these terms and conditions shall not be treated as a waiver of that provision, nor shall it affect that party’s right to subsequently enforce that provision. If any provision of these terms and conditions shall be invalid, void, illegal or unenforceable the validity, existence, legality and enforceability of the remaining provisions shall not be affected, prejudiced or impaired.
27.3 These terms and conditions and any contract to which they apply shall be governed by the laws of New Zealand and are subject to the jurisdiction of the Lower Hutt Court.
27.4 The Supplier shall be under no liability whatsoever to the Customer for any indirect and/or consequential loss and/or expense (including loss of profit) suffered by the Customer arising out of a breach by the Supplier of these terms and conditions (alternatively the Supplier’s liability shall be limited to damages which under no circumstances shall exceed the Price of the Goods).
27.5 The Supplier may licence and/or assign all or any part of its rights and/or obligations under this Contract without the Customer’s consent.
27.6 The Customer cannot licence or assign without the written approval of the Supplier.
27.7 The Supplier may elect to subcontract out any part of the Services but shall not be relieved from any liability or obligation under this Contract by so doing. Furthermore, the Customer agrees and understands that they have no authority to give any instruction to any of the Supplier’s sub-contractors without the authority of the Supplier.
27.8 The Customer agrees that the Supplier may amend their general terms and conditions for subsequent future contracts with the Customer by disclosing such to the Customer in writing. These changes shall be deemed to take effect from the date on which the Customer accepts such changes, or otherwise at such time as the Customer makes a further request for the Supplier to provide Goods and/or Services to the Customer.
27.9 Neither party shall be liable for any default due to any act of God, war, terrorism, strike, lock-out, industrial action, fire, flood, storm or other event beyond the reasonable control of either party.
27.10 Both parties warrant that they have the power to enter into this Contract and have obtained all necessary authorisations to allow them to do so, they are not insolvent and that this Contract creates binding and valid legal obligations on them.